Packet: Tiffin Regular City Council Meeting (05/19/2026)

STATEMENT OF BIDDER’S Project Name: Roberts Ferry Road & Village QUALIFICATIONS (CONT.) Drive Traffic Signal Improvements 2. Responsibility A. Has the Contractor’s Registration ever been suspended or revoked in any jurisdiction? Yes No If yes, provide all relevant information and documentation regarding the suspension or revocation. B. Has the Contractor ever been unable to obtain a bond or been denied a bond? Yes No If yes, provide all relevant information and documentation regarding the refusal or denial. C. Has the Contractor had any judgments entered against it or been a party to arbitration proceedings or litigation within the past five (5) years, or are there any currently pending arbitration proceedings or litigation involving the Contractor or any of its officers? Yes No If yes, provide listings, status, and outcomes regarding the judgments, arbitration proceedings, or litigation. The Owner reserves the right to request additional information, if deemed necessary. D. Within the past five (5) years, has the Contractor, or the Contractor’s proposed subcontractor(s) for the Project, ever been prohibited, debarred, disqualified, or removed by any federal, state, or local governmental entity from bidding on any project? Yes No If yes, provide all relevant information and documentation regarding the prohibition, debarment, disqualification, or removal. E. Within the past five (5) years, has the Contractor, or the Contractor’s proposed subcontractor(s) for the Project, received notification of breach or default on any contract; had any contract terminated; had any owner request to take over work; failed to substantially complete any project in a timely manner; or failed to fully complete any project in a timely manner? Yes No If yes, provide all relevant information and documentation regarding said breach, default, termination, owner request to take over work, or failure to complete. Statement of Bidder’s Qualifications SBQ-2 Roberts Ferry Road & Village Drive Traffic Signal Improvements